Federal contract award
36C10F20C0025
DALLAS FORT WORTH NATIONAL CEMETERY, PHASE 5, DESIGN-BID-BUILD
Award details
Obligations, current value and potential value describe different measures; they are never added together.
| Field | Reported value |
|---|---|
| Agency | Department of Veterans Affairs |
| Office | OFFICE OF CONSTRUCTION & FACILITIES MGMT (36C10F) |
| NAICS | 237990 — Other Heavy and Civil Engineering Construction |
| PSC | Y1PC — CONSTRUCTION OF UNIMPROVED REAL PROPERTY (LAND) |
| Parent award / vehicle | Not reported |
| Set-aside | SERVICE DISABLED VETERAN OWNED SMALL BUSINESS SET-ASIDE |
| Pricing type | FIRM FIXED PRICE |
| Obligations | $31.4M |
| Current contract value | $62.0M |
| Potential contract value / ceiling | $62.0M |
| Start date | Oct 19, 2020 |
| Current end date | Aug 4, 2026 |
| Potential end date | Aug 4, 2026 |
| Latest award activity | Aug 4, 2026 |
| Source loaded | Sep 26, 2026 |
Funding and modification history
Showing the latest 62 of 62 loaded transactions. Negative values are deobligations.
| Date | Modification | Obligation change | Description |
|---|---|---|---|
| Aug 4, 2026 | P00046 | $-6.4K | FINAL CONTRACT BOND ADJUSTMENT |
| Apr 6, 2026 | P00045 | $-330.2K | CONSTRUCTION PROJECT DE-SCOPE |
| Mar 26, 2025 | P00044 | $125.0K | PROVIDE STOCK PILE AND ROAD REPAIR |
| Feb 27, 2025 | P00043 | $60.4K | SERVICE PROVIDER SUPPLY ISSUES |
| Sep 30, 2024 | A00063 | $5.3K | DESIGN ERROR |
| Sep 30, 2024 | A00064 | $5.1K | SERVICE PROVIDER SUPPLY ISSUES |
| Aug 9, 2024 | A00062 | $43.4K | RESOLVE EXISTING CONDITION. |
| Jul 19, 2024 | A00058 | $0 | LIFE SAFETY |
| Jul 19, 2024 | A00059 | $0 | CONTRACTOR REQUESTED CHANGE. |
| Jul 19, 2024 | A00060 | $-3.9K | CAPTURE CREDITS FROM DESIGN/FIELD CHANGES |
| Jul 19, 2024 | A00061 | $0 | WEATHER DELAY MOD - NO COST |
| May 21, 2024 | A00057 | $0 | DESIGN ERRROR |
| May 7, 2024 | A00056 | $0 | WEATHER DELAY MOD - NO COST |
| May 1, 2024 | A00055 | $0 | CLIENT REQUEST AND CAPTURE CREDIT |
| Apr 22, 2024 | A00050 | $0 | DESIGN OMISSION |
| Apr 22, 2024 | A00051 | $0 | DESIGN ERROR/OMISSION |
| Apr 22, 2024 | A00052 | $0 | DIFFERING SITE CONDITION - INVESTIGATION FOR RESOLUTION |
| Apr 22, 2024 | A00053 | $0 | INTERNAL CHANGE TO REDUCE CLIENT MAINTENANCE |
| Apr 22, 2024 | A00054 | $0 | WEATHER DELAY MOD - NO COST |
| Mar 4, 2024 | A00043 | $0 | WEATHER DELAY MOD - NO COST |
| Mar 4, 2024 | A00044 | $2.8K | CLIENT REQUEST |
| Mar 4, 2024 | A00045 | $4.6K | UNFORESEEN CONDITION. |
| Mar 4, 2024 | A00046 | $9.2K | DIFFERING SITE CONDITION |
| Mar 4, 2024 | A00047 | $0 | DESIGN OMISSION |
| Mar 4, 2024 | A00049 | $0 | WEATHER DELAY MOD - NO COST |
| Feb 21, 2024 | P00041 | $272.5K | ADMINISTRATIVE: CHANGE OF CONTRACTING OFFICER |
| Feb 6, 2024 | A00048 | $3.8K | FUNDING CORRECTION |
| Jan 26, 2024 | A00040 | $39.9K | DESIGN OMISSION. |
| Jan 25, 2024 | A00033 | $24.7K | DIFFERING SITE CONDITION |
| Jan 25, 2024 | A00034 | $3.7K | DESIGN OMISSION |
| Jan 25, 2024 | A00035 | $0 | REQUESTED CHANGE BY CONTRACTOR. |
| Jan 25, 2024 | A00036 | $0 | CLIENT CHANGE REQUEST/DESIGN ERROR. |
| Jan 25, 2024 | A00037 | $0 | WEATHER DAY TIME EXTENSION |
| Jan 25, 2024 | A00038 | $2.6K | CLIENT REQUEST. |
| Jan 25, 2024 | A00039 | $213.3K | DESIGN OMISSION |
| Sep 7, 2023 | A00026 | $45.5K | DESIGN ERROR/OMISSION FOR THE AREA DRAINS AROUND THE NEW ADMINISTRATION BUILDING AND THE DOMESTIC WATER LINE. |
| Sep 7, 2023 | A00027 | $4.2K | FIELD ADJUSTMENT TO ALLOW FOR MORE ACCESSIBILITY FOR FUTURE MAINTENANCE FROM THE CLIENT. |
| Sep 7, 2023 | A00028 | $8.5K | DESIGN ERROR WITH NEW MAINTENANCE BUILDING LOCKER ROOM WINDOWS, SHOWER STALL REDESIGN AND CEMENT BACKER BOARD DEMOLITION. |
| Sep 7, 2023 | A00029 | $8.3K | DESIGN OMISSION OF ATTIC STOCK FOR ALL FINISHES WITHIN THE BASE CONTRACT. |
| Sep 7, 2023 | A00030 | $0 | DESIGN ERROR. CORRECTS ADA ACCESSIBILITY FOR MEN'S SHOWER STALL IN LOCKER ROOM. |
| Sep 7, 2023 | A00031 | $-50.2K | THIS MODIFICATION ADJUSTS THE DMARC ROUTING TO MITIGATE ANY NETWORK DOWNTIME THAT WOULD DISRUPT NCA OPERATIONS. |
| Sep 7, 2023 | A00032 | $0 | UNFORESEEN SITE CONDITION. |
| Aug 24, 2023 | A00025 | $73.9K | ADD A CONCRETE SLAB TO THE SOIL STORAGE BUILDING AND A SIDEWALK ADJOINING THE NEW NE PARKING LOT WITH THE EXISTING, IN ORDER TO PROVIDE SAFE EGRESS TO THE CLIENT. |
| Aug 22, 2023 | A00021 | $0 | WEATHER DELAY MODIFICATION TO INCORPORATE 20 NON COMPENSABLE CALENDAR DAYS OF TIME EXTENSION TO THE BASE CONTRACT. |
| Aug 22, 2023 | A00022 | $0 | WEATHER DELAY MODIFICATION TO INCORPORATE 2 NON COMPENSABLE CALENDAR DAYS OF TIME EXTENSION TO THE BASE CONTRACT. |
| Aug 22, 2023 | A00023 | $5.0K | BUDGET FOR REO INSPECTION TOOLS IN ORDER TO SUCCESSFULLY CARRY OUT DUTIES AND RESPONSIBILITIES. |
| Aug 22, 2023 | A00024 | $1.3K | ADDITIONAL KEY CYLINDERS FOR EXISTING FACILITIES TO TIE INTO THE NEW KEY SCHEDULE PROVIDED WITHIN THIS CONTRACT. |
| Jul 6, 2023 | P00020 | $0 | ADMINISTRATIVE: CHANGE OF ADMINISTRATIVE CONTRACTING OFFICER |
| May 22, 2023 | A00019 | $2.1K | REQUIRED BY NCA FOR CONTRACT PHASING. |
| Apr 25, 2023 | A00018 | $9.8K | MODIFICATION ADDRESSES DESIGN OMISSION OF THE PAINT FINISH FOR THE WOOD AWNING AROUND THE NEW ADMINISTRATION BUILDING. WILL NOW MATCH EXISTING FACILITIES. |
| Apr 18, 2023 | A00017 | $-2.9K | MODIFICATION CAPTURES THE CREDIT FOR A FIELD ADJUSTMENT ON THE SIZE OF THE NEW NE PARKING LOT AS A RESULT OF A DESIGN ERROR (CIVIL VS PLANTING PLAN). |
| Mar 3, 2023 | A00016 | $22.3K | MODIFICATION ADDRESSES A DESIGN ERROR AND OMISSION. SEGMENT OF THE SECONDARY CONDUITS FROM THE PAD MOUNTED TRANSFORMER WERE TO REMAIN HOWEVER DID NOT HAVE THE CAPACITY FOR THE NEW CONDUCTORS TO BE INSTALLED. |
| Nov 9, 2022 | P00010 | $0 | ADMINISTRATIVE: CHANGE OF CONTRACTING OFFICER |
| Sep 13, 2022 | A00008 | $129.0K | UNFORESEEN SITE CONDITIONS - NCA TRAILERS (IN CONTRACT) WERE IN A DETERIORATED STATE. THIS CHANGE COVERS LEASING COSTS FOR FOR NEW TRAILERS FOR CONTRACT PHASING. |
| Jul 15, 2022 | A00007 | $32.2K | DESIGN ERROR, ADDED WORK |
| Jul 7, 2022 | A00005 | $13.7K | DUE TO UNFORESEEN CONDITION, SLEEVING OF DRILLED PIERS WAS NEEDED AS THERE WAS WATER INTRUSION, EFFECTING CONCRETE POUR. |
| Jan 6, 2022 | P00006 | $3.0K | UNFORESEEN SITE CONDITIONS - ELECTRICAL CONDUIT DEFICIENCIES |
| Aug 23, 2021 | P00004 | $0 | CHANGE IN CO ADMINISTRATION |
| Dec 21, 2020 | P00003 | $0 | CHANGE IN CO ADMINISTRATION |
| Dec 7, 2020 | A00001 | $0 | RELOCATION OF RE OFFICE AT NO COST NO TIME DUE TO ISSUE OF CONTRACT LOCATION, CHANGED TO NEW LOCATION |
| Sep 30, 2020 | P00001 | $0 | DALLAS FORT WORTH NATIONAL CEMETERY, PHASE 5, DESIGN-BID-BUILD ADMINISTRATIVE MODIFICATION REFLECTING CORRECT PROJECT ADDRESS |
| Sep 28, 2020 | 0 | $30.6M | DALLAS FORT WORTH NATIONAL CEMETERY, PHASE 5, DESIGN-BID-BUILD |
Buyer contacts from matching notices
Matched on exact award/solicitation identifier and awarding agency. Source dates describe the notice, not current contact verification.
| Contact | Role | Published contact methods | Evidence | Source date |
|---|---|---|---|---|
| Crystal D. Cole | Contact | Crystal.Cole2@va.gov | Source | Jul 24, 2020 |
| Crystal D. Cole | Contact | Crystal.Cole2@va.gov | Source | Jul 22, 2020 |
| Crystal D. Cole | Contact | Crystal.Cole2@va.gov | Source | Jul 17, 2020 |
| Crystal D. Cole | Contact | Crystal.Cole2@va.gov | Source | Jul 17, 2020 |
| Crystal D. Cole | Contact | Crystal.Cole2@va.gov | Source | Jul 16, 2020 |
| Crystal D. Cole | Contact | Crystal.Cole2@va.gov | Source | Jul 15, 2020 |
| Crystal D. Cole | Contact | Crystal.Cole2@va.gov | Source | Jul 13, 2020 |
| Crystal D. Cole | Contact | Crystal.Cole2@va.gov | Source | Jul 9, 2020 |
| Crystal D. Cole | Contact | Crystal.Cole2@va.gov | Source | Apr 2, 2020 |
Research next steps
- Check the stated set-aside against the solicitation and current certifications.
- Review the award scope and buyer evidence before making a bid/no-bid decision.