Federal contract award
36C26321C0115
CONSTRUCTION SERVICES TO CONSTRUCT SEVEN STORY AIR HANDLING UNIT TOWER, PROJECT NUMBER 636-18-303 AT THE OMAHA DIVISION OF THE NEBRASKA-WESTERN IOWA HCS.
Award details
Obligations, current value and potential value describe different measures; they are never added together.
| Field | Reported value |
|---|---|
| Agency | Department of Veterans Affairs |
| Office | NETWORK CONTRACT OFFICE 23 (36C263) |
| NAICS | 236220 — Commercial and Institutional Building Construction |
| PSC | Z1DA — MAINTENANCE OF HOSPITALS AND INFIRMARIES |
| Parent award / vehicle | Not reported |
| Set-aside | SERVICE DISABLED VETERAN OWNED SMALL BUSINESS SET-ASIDE |
| Pricing type | FIRM FIXED PRICE |
| Obligations | $17.0M |
| Current contract value | $17.0M |
| Potential contract value / ceiling | $17.0M |
| Start date | Sep 21, 2021 |
| Current end date | Dec 23, 2025 |
| Potential end date | Dec 23, 2025 |
| Latest award activity | Oct 1, 2026 |
| Source loaded | Oct 17, 2026 |
Funding and modification history
Showing the latest 13 of 13 loaded transactions. Negative values are deobligations.
| Date | Modification | Obligation change | Description |
|---|---|---|---|
| Oct 1, 2026 | P00012 | $0 | P00012 - ADMIN MOD FOR EXPIRING FUNDS. CHANGING PO # FOR EXPIRING FUNDS. |
| Jul 24, 2026 | P00011 | $-268.3K | P00011 - MULTIPLY IN-SCOPE CHANGES FOR DIFFERING SITE CONDITIONS. |
| Oct 2, 2024 | P00010 | $0 | P00010 - LIFT SUSPENSION OF WORK |
| Sep 30, 2024 | P00009 | $0 | P00009 - SUSPENSION OF WORK ISSUED. |
| Mar 6, 2024 | P00008 | $142.2K | P00008 - ADD WITHIN SCOPE WORK DUE TO UNFORESEEN UNDERGROUND UTILITIES. |
| May 24, 2023 | P00007 | $3.1M | P00007 - ADD WITHIN SCOPE WORK DUE TO UNFORESEEN UNDERGROUND UTILITIES AND SETTLE A REQUEST FOR EQUITABLE ADJUSTMENT DUE TO DELAYS INCURRED THROUGH A SUSPENSION OF WORK. |
| Aug 24, 2022 | P00006 | $449.6K | P00006 - ADD WITHIN SCOPE WORK |
| Jun 28, 2022 | P00005 | $0 | P00004 - PARTIAL LIFT ON SUSPENSION OF WORK |
| Feb 28, 2022 | P00004 | $0 | P00004 - PARTIAL LIFT ON SUSPENSION OF WORK |
| Jan 26, 2022 | P00003 | $0 | PN: 636-18-303, CONSTRUCT AIR HANDLING TOWER, OMAHA VA MEDICAL CENTER. |
| Dec 13, 2021 | P00002 | $0 | PN: 636-18-303, CONSTRUCT AIR HANDLING TOWER, OMAHA VA MEDICAL CENTER. |
| Dec 6, 2021 | P00001 | $0 | EO14042 - MODIFICATION IMPLEMENTING COVID SAFETY PROTOCOLS. |
| Sep 21, 2021 | 0 | $13.6M | CONSTRUCTION SERVICES TO CONSTRUCT SEVEN STORY AIR HANDLING UNIT TOWER, PROJECT NUMBER 636-18-303 AT THE OMAHA DIVISION OF THE NEBRASKA-WESTERN IOWA HCS. |
Buyer contacts from matching notices
Matched on exact award/solicitation identifier and awarding agency. Source dates describe the notice, not current contact verification.
| Contact | Role | Published contact methods | Evidence | Source date |
|---|---|---|---|---|
| Daniel Kinney Email: daniel.kinney@va.gov | Contracting Officer | daniel.kinney@va.gov 402-996-3537 | Source | Aug 5, 2021 |
| Gregg R. Sutcliffe | Contact | gregg.sutcliffe@va.gov 402-996-3536 | Source | Aug 5, 2021 |
| Daniel Kinney Email: daniel.kinney@va.gov | Contracting Officer | daniel.kinney@va.gov 402-996-3537 | Source | Aug 4, 2021 |
| Gregg R. Sutcliffe | Contact | gregg.sutcliffe@va.gov 402-996-3536 | Source | Aug 4, 2021 |
| Daniel Kinney Email: daniel.kinney@va.gov | Contracting Officer | daniel.kinney@va.gov 402-996-3537 | Source | Jul 29, 2021 |
| Gregg R. Sutcliffe | Contact | gregg.sutcliffe@va.gov 402-996-3536 | Source | Jul 29, 2021 |
| Daniel Kinney Email: daniel.kinney@va.gov | Contracting Officer | daniel.kinney@va.gov 402-996-3537 | Source | Jul 7, 2021 |
| Gregg R. Sutcliffe | Contact | gregg.sutcliffe@va.gov 402-996-3536 | Source | Jul 7, 2021 |
| Daniel Kinney Email: daniel.kinney@va.gov | Contracting Officer | daniel.kinney@va.gov 402-996-3537 | Source | Jun 25, 2021 |
| Gregg R. Sutcliffe | Contact | gregg.sutcliffe@va.gov 402-996-3536 | Source | Jun 25, 2021 |
| Cynda Rosa | Contracting Officer | Cynda.Rosa@va.gov 402 996-3534 | Source | May 28, 2021 |
| Cynda Rosa | NCO 23 Contracting Officer | Cynda.Rosa@va.gov 402-996-3534 | Source | May 17, 2021 |
| Cynda.Rosa@va.gov | Cynda Rosa | Cynda.Rosa@va.gov 402-599-2168 | Source | Apr 2, 2021 |
Research next steps
- Check the stated set-aside against the solicitation and current certifications.
- Review the award scope and buyer evidence before making a bid/no-bid decision.